Preview
8/15/2019 5:10 PM
SHELLY D. MASTERS
Velva L. Price
COKINOS DIRECT 512-615-1139
EMAIL:
District Clerk
smasters@cokinoslaw.com
Travis County
D-1-GN-16-006178
Irene Silva
e
August 15, 2019
ic
Pr
Via E-filing and Email (andrew.williams2@traviscountytx.gov)
To the Honorable Karin Crump
L.
Drew Williams
Staff Attorney for the Honorable Karin Crump
a
250th District Court
lv
1000 Guadalupe St., 4th Floor
Ve
Austin, Texas 78701
k
Re: Cause No. D-1-GN-16-006178; John R. Keller Masonry, Inc. v. Weis Builders, Inc.
and Federal Insurance Company; et al. In the 250th District Court of Travis County,
er
Texas
Cl
Mr. Williams:
ct
Pursuant to Weis Builders, Inc.’s motion for leave to supplement the summary judgment
tri
record orally made and granted during yesterday’s hearing on 2013 Travis Oak Creek, LLC’s
Motions for Traditional and No-Evidence Summary Judgment, attached to this letter as Exhibit A
is
is the Amended Affidavit of Mike Biskupski wherein his testimony has been amended to withdraw
D
the mistaken representation that Pay Application 23 was unpaid and wherein, pursuant to Judge
Crump’s request, an Appendix item (no. 12) has been added to reflect the entire schedule of
.
Co
payments made to Weis Builders, Inc.
Thank you for your consideration of these matters.
is
av
Sincerely,
Tr
COKINOS | YOUNG
y
/s/ Shelly D. Masters
op
Shelly D. Masters
l c
ia
SDM
fic
Enclosure
of
cc: Via Email
Counsel of Record
Un
COKINOS I YOUNG 1210 Nueces Street, Austin, TX 78701 cokinoslaw.com
HOUSTON • SAN ANTONIO • AUSTIN • DALLAS/FT. WORTH
Un
of
fic
ia
l c op
y
Tr
av
is
Co
. D is
tri
ct
Cl
er
k
Ve
lv
EXHIBIT
a
A
L.
Pr
ic
e
Un
of
fic
ia
l c op
y
Tr
av
is
Co
. D is
tri
ct
Cl
er
k
Ve
lv
a
L.
Pr
ic
e
Un
of
fic
ia
l c op
y
Tr
av
is
Co
. D is
tri
ct
Cl
er
k
Ve
lv
a
L.
Pr
ic
e
APPENDIX 1
From: Paul Coplen
Sent: Monday, January 9, 2017 12:47 PM
e
To: Mark Rogers; 'Joe Tracy'; Travis Lucy
ic
Cc: Mike Biskupski; Derek Armstrong
Pr
Subject: RE: OCV - TDHCA Review
Attachments: OCV 145840- Owner Pay Application #26.pdf
L.
a
All,
lv
Please see attached final invoice for Oak Creek Village.
Ve
Thank you
k
Paul Coplen
er
Project Manager
Cl
Weis Builders, Inc.
520 E. Corporate Drive, #500 Lewisville, Texas 75057
DIRECT 469.444.6124 | TEL 469.464.3333 | CELL 612.418.5757 | FAX 469.464.3315
Stay Connected!
ct
tri
Facebook | LinkedIn | News | Twitter
Building Relationships Since 1939
D is
From: Paul Coplen
Sent: Thursday, December 22, 2016 2:18 PM
.
Co
To: 'Mark Rogers' ; 'Joe Tracy' ; Travis Lucy
Cc: Mike Biskupski ; Derek Armstrong
Subject: FW: OCV ‐ TDHCA Review
is
av
Resending the below and attached as the first email file was to large. I will be sending the letter issued to K. Chaiken in 3
separate emails. If that does not work I will send in a dropbox.
Tr
Thank you
y
Paul Coplen
op
Project Manager
c
Weis Builders, Inc.
520 E. Corporate Drive, #500 Lewisville, Texas 75057
DIRECT 469.444.6124 | TEL 469.464.3333 | CELL 612.418.5757 | FAX 469.464.3315
l
ia
Stay Connected!
fic
Facebook | LinkedIn | News | Twitter
Building Relationships Since 1939
of
From: Paul Coplen
Un
Sent: Thursday, December 22, 2016 1:54 PM
To: Travis Lucy ; 'Mark Rogers' ; 'Joe Tracy'
Cc: Mike Biskupski ; Derek Armstrong
Subject: RE: OCV ‐ TDHCA Review
1
We are in receipt of your most recent request for Weis to do additional warranty work. This request is problematic for
Weis for a number of reasons.
1. Weis has submitted pay applications #24 and #25 which have not been paid.
e
2. We have not received a response from you or your counsel from our August 19th, 2016 letter. Without recapping
ic
the full letter we made it clear that the failure to make payments has put you in breach of contract. Weis is not
Pr
obligated to perform any further work until this dispute is resolved.
L.
3. Attached Owner Change Orders #16 and #17 will need to be signed.
a
4. Weis Builders is and has been willing to complete the final sealant punch list items. However, we have been
lv
instructed by ownership or the designated representative to not mobilize and complete any work related to the
stucco system.
Ve
5. Upon payment of application #24 and #25 for $3,043,659.48 Weis Builders will re‐mobilize to the project and
complete warranty items. Based on the recap in the attached you would still have $241,646.46 withheld on
k
Weis.
er
Cl
We are prepared to discuss any of the above items, for clarification, as we are eager to close out this project.
ct
Thank you tri
Paul Coplen
is
Project Manager
D
Weis Builders, Inc.
520 E. Corporate Drive, #500 Lewisville, Texas 75057
.
DIRECT 469.444.6124 | TEL 469.464.3333 | CELL 612.418.5757 | FAX 469.464.3315
Co
Stay Connected!
Facebook | LinkedIn | News | Twitter
is
Building Relationships Since 1939
av
From: Travis Lucy [mailto:travis@bcarc.com]
Sent: Wednesday, December 21, 2016 3:46 PM
Tr
To: Paul Coplen
Cc: Karl Meeks ; Mark Rogers
y
Subject: OCV ‐ TDHCA Review
op
Hi Paul -
c
Here is the TDHCA inspection report we discussed last week, including our comments on required
corrective measures and photographic documentation. Please read through it and give me and Mark
l
ia
a call when you're ready to schedule this work.
fic
Note that Eureka wishes to upload our documentation of these corrections no later than January
31st.
of
Un
Fortunately there's not a lot of work required on Weis's end - overall it's a good report.
Thank you,
Travis Lucy AIA
2
Bercy Chen Studio LP
1111 East 11th St. Ste. 200
Austin Texas, USA 78702
1-512-481-0092 (O) x03
1-512-658-6486 (M)
e
www.bcarc.com
ic
Pr
L.
a
lv
Ve
k
er
Cl
ct
tri
D is
.
Co
is
av
Tr
y
op
c
l
ia
fic
of
Un
3
APPENDIX 2
c e
P ri
L .
v a
l
Ve
r k
l e
t C
r i c
s t
D i
o .
C
i s
a v
Tr
p y
c o
a l
c i
f fi
n o
U
Un
of
fic
ia
l c op
y
Tr
av
is
Co
. D is
tri
ct
Cl
er
k
Ve
lv
a
L.
Pr
ic
e
Un
of
fic
ia
l c op
y
Tr
av
is
Co
. D is
tri
ct
Cl
er
k
Ve
lv
a
L.
Pr
ic
e
APPENDIX 3
YN
CHAIKEN 580
°"EG
TENNYSON
CHA
PKWY., SUITE 440
CH A KEN
1
I PLANO, TEXAS 75024
P 214-265-0250
A TTORNEYS r 214-265-1537
e
WWW.CHAIKENLAW.COM
ic
Pr
THIS IS A SETTLEMENT COMMUNICATION COVERED
BY RULE 408, TEXAS RULES OF EVIDENCE
L.
July 28, 2016
a
lv
Ve
Karl Meeks Via Email: karlmeeksoweisbuilders.com and
Weis Builders, Inc. Certgied Mail
k
1660 S. Stemmons Freeway, Suite 475
er
Dallas, Texas 75067
Cl
Re: Oak Creek Village Apartments (the "Project"); AIA Standard Form of
Agreement between 2013 Travis Oak Creek, L.P. ("Owner") and Weis
ct
Builders, Inc. ("Contractor") dated May 21, 2014 (the "Contract") and
General Conditions of the Contract for Construction ("General Conditions")
tri
Mr. Meeks:
is
Dear
D
We represent 2013 Travis Oak Creek, L.P. ("Owner"). We write on its behalf in
response to your recent payment applications (nos. 23 and 24) in connection with the Project.
.
Capitalized letter defined forth Contract.
Co
terms inthis have the same meaning as or set in the
As you know, Section 4.2 of the Contract required Contractor to Substantially Complete
IA of Project within within 490 calendar after
is
Phase the 344 calendar days, and Phase IB days
the June 14, 2014 commencement date. As you know, Sections 4.4 of the Contract and 8.2.1 of
av
the General Conditions both have a time-is-of-the-essence requirement. Contractor failed to
achieve Substantial Completion of Phases IA and IB on a timely basis, and it is our
Tr
understanding that there is an open and unsolved dispute regarding what the Substantial
Completion dates are and further, regarding the implication and consequences of the delays in
achieving Substantial Completion. Notably, the architect of record has never issued
y
a
Substantial Completion certificate,having rejected Contractor's contention that the Substantial
op
Completion dates were, respectively, August 14, 2015 (for Phase IA) and November 25, 2015
(for Phase IB). The contractual requirement of obtaining a Certificate of Substantial Completion
c
remains unsatisfied.
l
ia
Your attention isdirected to paragraph 4.4 of the Contract, which prescribes a schedule of
Liquidated Damages that are due and owing by Contractor to Owner in connection with the
fic
untimely Substantial Completion of Phases IA and IB. Phase IA was due to be Substantially
Complete by May 14, 2015. Itwas not Substantially Complete until, atthe earliest, August 14,
of
2015. Owner was willing, atContractor's request, to consider Phase IA Substantially Complete
Un
EXHIBIT
2013 TOC LP016617
Karl Meeks y
Weis Builders,Inc.
Page 2
July28,20 16
e
ic
as of August 14, 2015, in reliance upon Contractor's representation that Substantial Completion
Pr
of Phase 1B would be complete by no later than November 17, 2015, and provided that
Contractor reached Substantial Completion of Phase IB by no later than November 17, 2015
(which beyond Contract date of October 2015). Phase IB not
L.
was a date the due 7, was
Substantially Complete, by any definition, on November 17, 2015 and was not Substantially
Complete until, at the earliest, February 28, 2016. Accordingly, Owner is owed the following
a
Liquidated Damages pursuant to Section 4.4 of the Contract:
lv
Ve
Phase IA: 1. $50,000.00 (first five days of delay (May 14-20, 2015));
2. $30,000.00 ($1000.00 per day for next 30 days-May 21-June 21);
and,
k
3. $212,000.00 ($4,000.00 per day from June 21"'to August 14 ).
er
Sub-Total: $292,000.00
Cl
Phase IB: 1. $50,000.00 (first five days of delay (November 17-23, 2015));
$30,000.00 ($1000.00 per
ct
2. day for the next 30 days); and,
3. $232,000.00 ($4,000.00 per day from December 23-February 28,
tri
2016).
is
Sub-Total: $312,000.00
D
TOTAL $604,000.00
.
Co
Owner hereby assesses $604,000.00 to Contractor as Liquidated Damages, according to Section
4.4 of the Contract, and exercises its right tooffset this amount against any sums due or claimed
due by Contractor under the Contract, pursuant to Section 8.2.4.1 of the General Conditions.
is
Section 4.4 of the Contract not an exclusive remedies provision, and Owner has
av
is
suffered actual direct damages due to Contractor's delays in achieving Substantial Completion.
More particularly, Owner suffered rental and utility expenses and loss of rental income during
Tr
the delay period, totaling approximately $l,133,291.00--damages which Owner attributes to and
seeks to recover from Contract, via offset or the assertion of a claim.
py
Additionally, and as Contractor is aware, throughout the Project stucco was defectively
requires Contractor
co
applied, and now substantial remediation. We understand that denies this
outright and/or refuses to correct and cure these defects at all,or in a satisfactory manner, as a
warranty item or otherwise. At this time, Owner estimates a remediation cost of between $1
al
million and $2 million to resolve this defective stucco work, depending upon the outcome of its
investigation.
i
fic
Contractor also has failed and isrefusing to complete a number of open punch listitems,
which has Owner to remediation cost. Contractor
of
caused incur approximately $50,000.00 in And,
Un
2013 TOC LP0166l8
Karl Meeks
Weis Builders,Inc.
Page 3
July28,2016
e
ic
has been unable to remediate a water intrusion problem affecting the Project's garage, as a
Pr
warranty items or otherwise, giving rise to an estimated cost of remediation of approximately
$500,000.00 given what iscurrently known about the problem.
L.
You are advised that Contractor's payment application no. 23 in the amount of
approximately $43,000.00 will be processed for payment without waiver by Owner of any rights,
a
complaints or claims or defenses.
lv
Ve
You are advised that Contractor's payment application no. 24 will not be paid, for the
following reasons:
k
1. Contractor has failed to submit a proper final accounting as required by the
er
Contract;
Cl
2. Contractor has failed to satisfy some or all of the material requirements of
Section 9.10.2 of the General Conditions;
3. The Contract does notpermit a partial final
ct
payment application; and,
tri
4. Owner is entitled to recover the Liquidated Damages and other damages
is
described above from Contractor, and/or to offset the total sum of the same
remaining claimed Contractor, in the of
D
against any sums due by way
retainage or otherwise, and the total amount of Owner's claims against
Contractor apparently claims
.
Contractor exceeds the total amount that is due
Co